![]() |
Code of Federal Regulations (Last Updated: July 5, 2024) |
![]() |
Title 48 - Federal Acquisition Regulations System |
![]() |
Chapter 1 - Federal Acquisition Regulation |
![]() |
SubChapter G - Contract Management |
![]() |
Part 42 - Contract Administration and Audit Services |
![]() |
Subpart 42.13 - Suspension of Work, Stop-Work Orders, and Government Delay of Work |
§ 42.1302 - Suspension of work.
Latest version.
-
42.1302 Suspension of work.
A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.