![]() |
Code of Federal Regulations (Last Updated: July 5, 2024) |
![]() |
Title 48 - Federal Acquisition Regulations System |
![]() |
Chapter 13 - Department of Commerce |
![]() |
SubChapter C - Contracting Methods and Contract Types |
![]() |
Part 1317 - Special Contracting Methods |
![]() |
Subpart 1317.70 - Contracts for Ship Construction, Ship Alteration, and Ship Repair |
§ 1317.7001 - Solicitation provisions and contract clauses.
-
(a)(1) The contracting officer shall insert the following clauses in sealed bid fixed-price solicitations and contracts for ship construction, ship alteration, and ship repair.
(i) Inspection and Manner of Doing Work, 1352.217-90.
(ii) Delivery of the Vessel to the Contractor, 1352.217-91.
(iii) Performance, 1352.217-92.
(iv) Delays, 1352.217-93.
(v) Minimization of Delay Due to Government Furnished Property, 1352.217-94.
(vi) Additional Provisions Relating to Government Property, 1352.217-95.
(vii) Liability and Insurance, 1352.217-96.
(viii) Title, 1352.217-97.
(ix) Discharge of Liens, 1352.217-98.
(x) Department of Labor Occupational Safety and Health Standards for Ship Repairing, 1352.217-99.
(xi) Regulations Governing Asbestos Work, 1352.217-100.
(xii) Complete and Final Equitable Adjustments, 1352.217-101.
(xiii) Government Review, Comment, Acceptance, and Approval, 1352.217-102.
(xiv) Access to the Vessel, 1352.217-103.
(xv) Documentation of Requests for Equitable Adjustment, 1352.217-104.
(xvi) Change Proposals, 1352.217-105.
(xvii) Lay Days, 1352.217-106.
(xviii) Changes—Ship Repair, 1352.217-107.
(xix) Default—Ship Repair, 1352.217-108.
(2) Unless inappropriate due to contract type, the contracting officer shall insert the clauses listed above in negotiated solicitations and contracts for ship construction, ship alteration, and ship repair.
(b) The contracting officer shall insert a clause substantially the same as the clause at 1352.217-109, Insurance Requirements, in solicitations and contracts for ship construction, ship alteration, and ship repair, unless the contracting officer determines that the contract, or job order, requires work on parts of a vessel only and the work is to be performed at a plant other than the site of the vessel.
(c) The contracting officer shall insert the clause at 1352.217-110, Guarantees, unless the contracting officer determines that its use would be inappropriate under the circumstances.
(d) The contracting officer shall insert the clause at 1352.217-111, Temporary Services, in solicitations and contracts for ship construction, ship alteration, and ship repair, unless the contracting officer determines that its use would be inappropriate under the circumstances.
(e) The contracting officer shall insert the provision at 1352.217-112, Self-Insurance Information, in solicitations and contracts for ship construction, ship alteration, and ship repair, when the contracting officer determines that it is appropriate to allow offerors the opportunity to self-insure for any or all of the risks set forth in the applicable insurance clauses of the contract.