§ 836.206 - Liquidated damages.

836.206 Liquidated damages.

Cross Reference

Link to an amendment published at 84 FR 9972, Mar. 19, 2019.

The contracting officer may include a liquidated damages provision in a construction contract when the criteria of FAR 11.501 and 811.501 are met. If partial performance may be accepted and used to the advantage of the Government, the contracting officer must include the clause substantially as set forth in 852.211-74, Liquidated Damages, in addition to the clause set forth in FAR 52.211-12.